home Internet professions Contract of services for the provision of a part of the exhibition stand. Business portal of the path to success. Legal addresses and details of the parties

Contract of services for the provision of a part of the exhibition stand. Business portal of the path to success. Legal addresses and details of the parties

booth during the exhibition in a person acting on the basis of , hereinafter referred to as " Organizer”, on the one hand, and in the person acting on the basis of , hereinafter referred to as “ Participant”, on the other hand, hereinafter referred to as the “Parties”, have concluded this agreement, hereinafter “ Treaty" about the following:

CONTRACT N ____
for design and installation work
exhibition stand
G. _________
"___"_______ _____ G.
____________, hereinafter referred to as __ "Customer", represented by _______________, acting ___ on the basis of _____________, on the one hand, and ________________, hereinafter referred to as __ "Contractor", represented by ______, acting ___ on the basis of _______________, on the other hand, have concluded this Agreement on the following :
1. THE SUBJECT OF THE AGREEMENT
1.1. The Customer instructs, and the Contractor undertakes to perform the installation of an exhibition stand with a floor area of _________ sq. m, at the exhibition _________________, which will be held from "___" _______ _____ to "___" _______ ____ in ____________ on the street. __________, ______ in _______________, as well as the dismantling of the stand at the end of the above exhibition.
1.2. The customer undertakes to accept and pay for the work performed.
2. OBLIGATIONS OF THE PARTIES
2.1. The Contractor, in accordance with clause 1.1, undertakes to fulfill following works:
- develop preliminary design on the basis of the Customer's terms of reference with the binding of the exhibition stand to the place at the exhibition;
- purchase the necessary property and materials;
- carry out turnkey installation of the above stand using our own equipment;
- artistically arrange the stand in accordance with the agreed terms of reference and the original layout;
- lease property and materials to the Customer for the duration of the exhibition according to the estimate;
- hand over the stand to the Customer with the execution of all his comments no later than _______ hours "__" _______ ___;
- to dismantle the stand after the end of the exhibition with the timely removal of the stand components within the time limits set by the organizers of the exhibition;
- transfer to the Customer the ownership at his request of any property and materials, with the exception of those that were leased by the Contractor in accordance with the estimate attached to this Agreement.
2.2. The customer, in accordance with clause 1.1, undertakes:
- provide the Contractor with all the necessary information for linking the exhibition stand and decoration;
- order and provide the Contractor with an exhibition area of ______ sq. m for the conduct of assembly and dismantling works within the time limits set by the organizers of the exhibition;
- order and pay for the connection of power supply, water supply and telephone installation of the stand from the organizers of the exhibition;
- no later than ____ hours before the opening of the exhibition to express their comments on appearance stand and, if there are none, accept a stand for mounting exhibits, which is confirmed by the relevant act;
- timely pay for the work of the Contractor within the time limits stipulated by this Agreement;
- in case of making changes to the approved project of the exhibition stand during the installation work, pay a double tariff for additional services according to the existing price list of the Contractor, if the corresponding changes in the project entail the need to remake already installed parts of the stand.
3. COST OF WORKS
3.1. The cost of works and services agreed in clause 2.1 of this Agreement is _____________, including VAT.
The cost of each type of work and services is indicated in the estimate.
The above amount of this Agreement is a fixed amount, includes the Contractor's remuneration, the cost of consumables, other costs of the Contractor under this Agreement, the cost of renting the property provided by the Contractor, etc. expenses.
Payment is made in rubles on the basis of the Contractor's invoice at the current exchange rate of the Central Bank of the Russian Federation on the date of invoicing.
3.2. Payment of the amount specified in clause 3.1 of this Agreement is carried out by the Contractor in two payments in the following order:
3.2.1. ____% of the amount - within __ banking days from the date of conclusion of this Agreement.
3.2.2. Remaining __% of total amount of this Agreement - within ___ banking days from the date of signing by the parties of the act of acceptance of the work and services performed.
4. RESPONSIBILITIES OF THE PARTIES
4.1. In case of violation of the payment terms (see clause 3.2) due to the fault of the Customer (excluding force majeure circumstances), the Customer shall pay the Contractor a penalty (penalty) in the amount of _____% of the amount of this Agreement for each day of delay.
4.2. In case of non-fulfillment of obligations under this Agreement by the Contractor, i.e. the absence of a properly designed exhibition stand by the official opening of the exhibition due to the fault of the Contractor (excluding force majeure circumstances), the Contractor shall return the amount advanced by the Customer to his account within ____ banking days from the date the Customer made a relevant claim to the Contractor, and this Agreement is terminated. In the event of a delay in the fulfillment of this condition, the Contractor shall pay a penalty (penalty) in the amount of ____% of the advance payment for each day of delay.
At the same time, if the Customer does not take part in the exhibition due to the fault of the Contractor, the Contractor will be obliged to pay a fine to the Customer in the amount of ___________.
4.3. For violation of the terms for dismantling the stand after the end of the exhibition and the timely removal of stand components and other materials and property within the time limits established by the organizers of the exhibition, the Contractor shall be liable and pay the Customer a fine in the amount of _________________.
5. FORCE MAJOR
5.1. The Parties are released from liability for partial or complete failure to fulfill obligations under the Agreement, if this failure was the result of force majeure circumstances and / or their consequences (hereinafter referred to as "force majeure"), provided that these circumstances arose after the conclusion of the Agreement and directly affected the fulfillment by the parties of their obligations.
5.2. The following events are recognized as force majeure under this Agreement: fire, flood, earthquake and other natural disasters, epidemics, hostilities and regulatory instructions of state bodies that are binding on at least one of the parties, which the parties could neither foresee nor prevent by all available them with reasonable measures.
5.3. In cases of occurrence of force majeure, as well as at the end of its validity period, the party whose performance of obligations is affected by these circumstances is obliged to send a corresponding written notice to the other party within three days, otherwise it will not be entitled to refer to force majeure as circumstances exempting it from liability for violation of this Agreement.
5.4. Proper evidence of the existence of force majeure circumstances and their duration will be the relevant certificates of state bodies.
6. DISPUTES RESOLUTION
6.1. In the event of disputes between the parties during the execution of this Agreement, the parties will take all measures to resolve them through negotiations, and if no agreement is reached, the dispute will be referred to the Arbitration Court of _________ in the manner prescribed by law.
7. OTHER TERMS
7.1. In all other respects that are not provided for by this Agreement, the parties are guided by the current legislation of the Russian Federation.
7.1. The parties undertake to immediately inform each other of any difficulties that may lead to non-fulfillment separate conditions of this Agreement, to agree and take the necessary measures.
7.2. All commercial, design and technical documentation transferred by the Customer to the Contractor or compiled by the Contractor in agreement with the Customer, necessary for the performance of works and services, is an Appendix to this Agreement and any changes in it can be made only by mutual agreement of the parties.
7.3. The equipment and property purchased by the Contractor in pursuance of this Agreement are the property of the Customer, with the exception of that which was leased to the Customer according to the estimate.
7.4. The customer has the right to place advertising, trademarks and other information on the rented surfaces of the stand at his own discretion, provided that after the end of the exhibition it is removed by him without damaging the exhibition equipment.
Permissible ways of placing advertising, trademarks and other information on the surfaces of the stand are previously agreed with the Contractor in writing.
7.5. In case of damage or loss of the rented exhibition property in whole or in any part during the exhibition, the Customer shall pay the Contractor a penalty in the amount of full cost damaged or lost equipment.
8. DETAILS OF THE PARTIES
Performer: Customer:
___________________________ ______________________________
___________________________ ______________________________
___________________________ ______________________________
___________________________ ______________________________
___________________________ ______________________________
SIGNATURES OF THE PARTIES:
From the Customer: From the Contractor:
________________________ ________________________
(position) (position)
______________/_________ ______________/_________
(Full name, signature) (Full name, signature)
M.P. M.P.

in a person acting on the basis of , hereinafter referred to as " Organizer”, on the one hand, and in the person acting on the basis of , hereinafter referred to as “ Participant”, on the other hand, hereinafter referred to as “ Parties”, have concluded this agreement, hereinafter referred to as the “Agreement”, as follows:

LEGAL ADDRESSES AND DETAILS OF THE PARTIES

Organizer

Participant

G. ______________

"___"________ ___ G.

____________________________, hereinafter referred to as __ "Customer", represented by (name or full name) ___________________, acting ___ on the basis of ___________________________, (position, full name) (Charter, regulation, power of attorney or passport) on the one hand , and ________________________________, hereinafter referred to as __ (name or full name) "Contractor", represented by ___________________________, acting ___ on the basis of (position, full name) ______________________________________________, on the other hand, have concluded (Charter, regulations, power of attorney or passport) this Agreement as follows:

1. THE SUBJECT OF THE AGREEMENT

1.1. The Contractor undertakes to perform, according to the Order of the Customer (Appendix N __ to this Agreement), the installation of an exhibition stand with a floor area of ______ sq. m at the exhibition ____________, which will be held from "___" ________ ___ to "___" _______ ___ in ____________ on the street. __________, _____ in _____________, as well as dismantling the stand at the end of the above exhibition.

1.2. The customer undertakes to accept and pay for the work performed.

1.3. Works are carried out at the place of the exhibition, specified in clause 1.1 of this Agreement.

2. OBLIGATIONS OF THE PARTIES

2.1. The Contractor, in accordance with clause 1.1, undertakes to perform the following works:

Develop a draft design of an exhibition stand based on the Customer's Order;

Purchase the following property: _________________, materials: _____________________;

To carry out installation of the exhibition stand using own equipment;

Artistically decorate the exhibition stand in accordance with the agreed task of the Customer and the original layout;

Hand over the exhibition stand to the Customer no later than ______ hours "___" _________ ___;

To dismantle the exhibition stand after the end of the exhibition within _______ from the moment of its end.

The Contractor undertakes to begin work no later than ______ from the date of receipt of the Customer's order. The purchase of materials necessary for the implementation of this Agreement, as well as the development by the Contractor of a draft design of the exhibition stand must be completed no later than "___" ________ ___. Installation and design of the exhibition stand must be completed by the Contractor no later than "___" ________ ___.

The works listed in this paragraph, the Contractor undertakes to perform within the time agreed with the Customer and specified in the work schedule (Appendix N __), which is an integral part of this Agreement.

2.2. The customer, in accordance with clause 1.1, undertakes:

Not later than _______ from the moment of signing by the Parties of this Agreement, provide the Contractor with the Customer's task;

Provide the Contractor with access to the exhibition premises for assembly and dismantling within the ________ period;

Approve the draft design of the exhibition stand developed by the Contractor within ______ from the receipt of the draft design;

Not later than ______, accept the exhibition stand according to the certificate of completion (Appendix N ___), which is an integral part of this Agreement;

Make payment for the work of the Contractor within the time limits stipulated by this Agreement.

2.3. In case of cancellation of this Agreement, the Customer is obliged to pay for the actually performed work.

3. COST OF WORKS

3.1. The cost of each type of work is indicated in the estimate (Appendix N __), which is an integral part of this Agreement.

The above amount of this Agreement is a fixed amount, includes payment for the work performed by the Contractor, the cost of consumables.

3.2. Payment of the amount specified in clause 3.1 of this Agreement is carried out by the Customer in two payments in the following order:

3.2.1. ____% of the amount - within __ banking days from the date of conclusion of this Agreement.

3.2.2. The remaining ____% of the total amount of this Agreement - within _____ banking days from the date of signing by the parties of the act of acceptance of the work performed.

4. RESPONSIBILITIES OF THE PARTIES

4.1. In case of violation of the terms of payment (see clause 3.2) through the fault of the Customer (excluding force majeure circumstances), the Contractor has the right to require the Customer to pay a penalty in the amount and on the terms provided for by the current legislation of the Russian Federation.

4.2. In case of non-fulfillment of obligations under this Agreement by the Contractor, i.e. the absence of a properly designed exhibition stand by the official opening of the exhibition due to the fault of the Contractor (excluding circumstances of force majeure), the Customer has the right to demand from the Contractor compensation for losses incurred by the Customer due to non-participation in the exhibition, as well as to demand from the Contractor the return of the advance paid by the Customer and termination actual agreement. The claim for damages and return of the advance amount must be fulfilled by the Contractor within ____ banking days from the date of receipt of the Customer's claim.

4.3. In case of violation of the term for dismantling the stand established by this Agreement after the end of the exhibition, the Customer has the right to demand from the Contractor the immediate dismantling of the stand and payment of a penalty in the amount of ________ rubles. for each day of delay.

5. FORCE MAJOR

5.1. The Parties are released from liability for partial or complete failure to fulfill obligations under the Agreement, if this failure was the result of force majeure circumstances and / or their consequences (hereinafter referred to as "force majeure"), provided that these circumstances arose after the conclusion of the Agreement and directly affected the fulfillment by the parties of their obligations.

5.2. The following events are recognized as force majeure under this Agreement: fire, flood, earthquake and other natural disasters, epidemics, military operations.

5.3. In cases of force majeure, the party whose performance of obligations is affected by these circumstances is obliged to send the other party an appropriate written notice within the period _________, otherwise it will not be entitled to refer to force majeure as circumstances relieving it from liability for violation actual agreement.

5.4. Proper evidence of the existence of force majeure circumstances and their duration will be the relevant certificates of state bodies.

6. DISPUTES RESOLUTION

6.1. In the event of disputes between the parties during the execution of this Agreement, the parties will take all measures to resolve them through negotiations, and in case of failure to reach an agreement, the dispute will be referred to the court in accordance with the procedure established by law.

7. OTHER TERMS

7.1. In all other respects that are not provided for by this Agreement, the parties are guided by the current legislation of the Russian Federation.

7.2. The Parties undertake to immediately inform each other about the difficulties that may arise, which may lead to non-fulfillment of certain conditions of this Agreement, in order to agree and take the necessary measures.

7.3. All commercial, design and technical documentation transferred by the Customer to the Contractor or compiled by the Contractor in agreement with the Customer, necessary for the performance of works and services, is an Appendix to this Agreement, and any changes in it can be made only by mutual agreement of the parties.

8. DETAILS OF THE PARTIES

Contractor: Customer: _________________________________ ______________________________ _________________________________ ______________________________ _________________________________ ______________________________ ___________________________ ______________________________ _________________________________ ______________________________ ________________________________ ______________________________ SIGNATURES OF THE PARTIES: Contractor: Customer: ________________________________ ______________________________ (position) (position) ______________/___________ _____________/________________ (full name, signature) (F. I.O., signature) M.P. M.P.